A recent decision by the Armed Services Board of Contract Appeals illustrates the importance for GCs to obtain solid commitments from key subcontractors when seeking government contracts.
The ASBCA earlier this year dismissed a construction contractor’s claim for increased costs on a contract for the construction of dissolved oxygen injection systems in the Savannah River. The case involved a GC whose marine subcontractor withdrew its bid after a delay.
The contractor subsequently said that it would incur more than $3 million in increased costs. The ASBCA ruled that there was no evidence that the suspension of about 60 days to resolve a bid protest was anything but reasonable.
It also found that there was no causal connection between the suspension and the GC’s increased costs. The key lesson: prime contractors should promptly execute subcontracts with key subcontractors.
Related Stories
Codes and Standards | Sep 21, 2020
No ease of lumber price spikes in sight
Wildfires strike Northwest timber industry in wake of Covid-19 shutdowns.
Codes and Standards | Sep 17, 2020
Spate of energy code appeals could hamper efficiency progress
Construction and fossil fuel interests oppose portions of latest model energy code.
Codes and Standards | Sep 16, 2020
Heat pumps are the future for hot water
Sustainability policies will drive trend.
Codes and Standards | Sep 15, 2020
Taller timber buildings approved in National Fire Protection Association code
Ensures compatibility with the International Building Code.
Codes and Standards | Sep 14, 2020
Relocation of neighborhoods, the next step in U.S. flood strategy, is underway
Repeated rebuilding after successive floods now seen as bad policy.
Codes and Standards | Sep 10, 2020
Fannie Mae programs provide incentives for multifamily solar
Affordable housing projects can find PV installations to be cost-effective.
Codes and Standards | Sep 9, 2020
Corporate pledges accelerate net-zero building movement
World Green Building Council drives goal of net-zero carbon emissions by 2050.
Codes and Standards | Sep 8, 2020
Study will examine elevator airflow amid COVID-19 pandemic
Researchers to investigate risk of airborne transmission.
Codes and Standards | Sep 4, 2020
Updated selection, application guide for plastic glazed skylights, sloped glazing released
Part of suite of skylight documents by Fenestration and Glazing Industry Alliance.
Codes and Standards | Sep 3, 2020
Turner Construction takes strong stand against racism
Shuts down work sites for anti-bias training.