A recent decision by the Armed Services Board of Contract Appeals illustrates the importance for GCs to obtain solid commitments from key subcontractors when seeking government contracts.
The ASBCA earlier this year dismissed a construction contractor’s claim for increased costs on a contract for the construction of dissolved oxygen injection systems in the Savannah River. The case involved a GC whose marine subcontractor withdrew its bid after a delay.
The contractor subsequently said that it would incur more than $3 million in increased costs. The ASBCA ruled that there was no evidence that the suspension of about 60 days to resolve a bid protest was anything but reasonable.
It also found that there was no causal connection between the suspension and the GC’s increased costs. The key lesson: prime contractors should promptly execute subcontracts with key subcontractors.
Related Stories
Codes and Standards | Jan 30, 2017
Denser development could reduce emissions more than building energy retrofits
More tightly packed cities would cut building emissions significantly, study says.
Codes and Standards | Jan 27, 2017
Calif. legislator proposes statewide solar mandate for new buildings
It would be the first such requirement in the U.S.
Codes and Standards | Jan 25, 2017
Standard baseline for measuring building efficiency needed
EUI could push sustainability through market-driven approach.
Codes and Standards | Jan 23, 2017
Workers, local officials rally for new construction safety law in New York City
The new law would require those who work on 10-story-plus buildings to go through an apprenticeship program.
Codes and Standards | Jan 23, 2017
Prominent Atlanta construction executive faces charges in $1 million bribery scheme
The company has worked on some major projects, including Hartsfield Airport.
Codes and Standards | Jan 20, 2017
New resource lists green incentives by state
USGBC's new Public Policy Library includes tax and energy benchmarking policies.
Codes and Standards | Jan 18, 2017
How green leases benefit owners and tenants
Agreements to spur efficiency upgrades are slowly gaining popularity.
Codes and Standards | Jan 17, 2017
Intl. Code Council looks into code changes for cross-laminated timber structures
Most codes limit CLT structures’ height.
Codes and Standards | Jan 16, 2017
Building codes for existing buildings evaluated in new white paper
The paper examines implementation, enforcement challenges, and changes needed in new code editions.
Codes and Standards | Jan 13, 2017
New BIM guide for owners released
National Institute of Building Sciences releases a manual for developing standard set of BIM documents.