A recent decision by the Armed Services Board of Contract Appeals illustrates the importance for GCs to obtain solid commitments from key subcontractors when seeking government contracts.
The ASBCA earlier this year dismissed a construction contractor’s claim for increased costs on a contract for the construction of dissolved oxygen injection systems in the Savannah River. The case involved a GC whose marine subcontractor withdrew its bid after a delay.
The contractor subsequently said that it would incur more than $3 million in increased costs. The ASBCA ruled that there was no evidence that the suspension of about 60 days to resolve a bid protest was anything but reasonable.
It also found that there was no causal connection between the suspension and the GC’s increased costs. The key lesson: prime contractors should promptly execute subcontracts with key subcontractors.
Related Stories
Codes and Standards | Jan 31, 2018
California is the first state to phase out incandescent light bulbs
In two years, the rest of the U.S. will follow suit.
Codes and Standards | Jan 31, 2018
Automated tool assists in design of force transfer around openings
Engineered Wood Assn. offers free calculator and technical note.
Codes and Standards | Jan 31, 2018
First large-scale use of perovskite solar cells in office building slated for Poland this year
Skanska will integrate the technology into building facades.
Codes and Standards | Jan 29, 2018
Advanced Energy Design Guide for K-12 Schools to achieve zero energy
Publication is joint effort by ASHRAE, AIA, IES, and USGBC.
Codes and Standards | Jan 26, 2018
Flying drones while inebriated now illegal in New Jersey
Violators could be sentenced to six months in jail.
Codes and Standards | Jan 25, 2018
OSHA penalties for violations increase
Fines adjusted for inflation in the New Year.
Codes and Standards | Jan 23, 2018
Disaster mitigation strategies that exceed code could save billions
Four dollars saved for every dollar spent, says NIBS report.
Codes and Standards | Jan 19, 2018
U.S. construction fatalities rose 6% in 2016
Falls accounted for 39% of deadly accidents.
Codes and Standards | Jan 18, 2018
Record storm surge in Boston prompts renewed calls for flood mitigation infrastructure
Newer buildings constructed in flood zone fared well.
Codes and Standards | Jan 17, 2018
Green Building Initiative acquires global rights to Green Globes from JLL
Transaction allows GBI to expand operations to Canada and elsewhere.