A recent decision by the Armed Services Board of Contract Appeals illustrates the importance for GCs to obtain solid commitments from key subcontractors when seeking government contracts.
The ASBCA earlier this year dismissed a construction contractor’s claim for increased costs on a contract for the construction of dissolved oxygen injection systems in the Savannah River. The case involved a GC whose marine subcontractor withdrew its bid after a delay.
The contractor subsequently said that it would incur more than $3 million in increased costs. The ASBCA ruled that there was no evidence that the suspension of about 60 days to resolve a bid protest was anything but reasonable.
It also found that there was no causal connection between the suspension and the GC’s increased costs. The key lesson: prime contractors should promptly execute subcontracts with key subcontractors.
Related Stories
Codes and Standards | Feb 14, 2019
ISO publishes first global BIM standards
Based on British standard and a publicly available standard.
Codes and Standards | Feb 12, 2019
Property technology adoption accelerates in commercial real estate industry
New business models create disintermediation.
Codes and Standards | Feb 11, 2019
Investing in downtowns pays off for cities, regions
Benefits include driving tax revenue, business activity, and smart development.
Codes and Standards | Feb 8, 2019
Oslo, Norway’s downtown goes virtually car-free
Parking spots converted to bike lanes, transit is fast and easy.
Codes and Standards | Feb 7, 2019
New North Carolina energy code has extensive lighting control requirements
Includes automatic shut offs for buildings of all sizes.
Codes and Standards | Feb 6, 2019
Solar carports can help with California’s Title 24 mandates
Can be combined with virtual net-metering software and tax-enabled financing.
Codes and Standards | Feb 5, 2019
Milwaukee board approves rezoning for Western Hemisphere’s tallest mass timber building
Mixed-use tower would rise 21 stories high.
Codes and Standards | Feb 1, 2019
Mass. governor proposes real estate transfer fee hike for climate resiliency projects
Opposed by real estate and trade groups, plan could generate $1 billion in next decade.
Codes and Standards | Jan 31, 2019
New York City will reform construction bid process
Streamlined process intended to improve efficiency, reduce hassle for bidders.
Codes and Standards | Jan 30, 2019
New AGC program aims to diversify construction workforce
More diversity needed to keep pace with demand for workers.
